Terms and conditions

Last updated: 14 November 2026

These terms govern your use of the Dtechno website and any web development, SaaS development or care plan services we provide. By using this website or engaging our services, you agree to these terms.

1. Services

We design, develop, deploy and maintain websites and software products. The exact deliverables, timeline and fees for each project are set out in a written proposal or quote that you accept before work begins.

2. Quotes and payments

Quotes are valid for 30 days. Projects are billed in milestones as stated in the proposal, typically an advance before work starts and the balance across design approval and launch. Care plans are billed monthly in advance. Invoices are payable within 7 days unless agreed otherwise.

3. Client responsibilities

You agree to provide content, feedback, access and approvals on time. Delays in providing these may move the delivery date. You confirm that any content you supply does not infringe anyone else's rights.

4. Changes to scope

Requests outside the agreed scope are quoted separately and added only after your written approval.

5. Ownership

Once all payments are received, you own the final code, designs and content created for your project. Third-party software, libraries, fonts and services remain subject to their own licences. We may show the finished work in our portfolio unless you ask us not to.

6. Warranty and support

We fix bugs reported within 30 days of launch at no charge. After that, support is provided under a care plan or at our standard rates.

7. Limitation of liability

We are not liable for indirect or consequential losses, including lost profit or data. Our total liability for any project is limited to the amount you paid for that project.

8. Termination

Either party may end a project with written notice. You pay for work completed up to that date, and refunds follow our Refund policy.

9. Governing law

These terms are governed by the laws of India, and disputes are subject to the jurisdiction of the courts in Surat, Gujarat.

10. Contact

Questions about these terms can be sent to hello@dtechno.dev or by post to: Dtechno, 1698, Shreeram Nagar, G.H. Board, Chhaprabhatha Road, Amroli, Chorasi, Surat, Gujarat – 394107, India.